Saturday, February 16, 2008

Twisted Colon Symptoms

500 days / Farewell and close

The time has come close down this blog , having already served the purpose of it, which is quite simply to tell, as the subtitle, the "noir some works annoying, expensive and unnecessary in Collado Villalba (Madrid), who mortgaged the city for 40 years for the benefit of usual. " Also, just today met 500 days since its creation, as seen in the counter end of the page. A round number to make the semi-final.

have been a total of 176 articles in these 500 days, seen so far more than 108,200 times by more than 42,000 unique visitors (half a day, 216 and 84 respectively) and have had 2,191 comments, most brilliant and / or interesting. Highlighting the fact that, despite the comments never had prior restraint on our part, but it could be published directly to any time of day or night, just had to delete another 9, which gives an idea of \u200b\u200b good level of education and respect for our visitors, of you @ s. Congratulations for that.

would be great to be opened new pages in this style to tell things that happen at street level. At least one in every neighborhood of Villalba. The tools are many and complex. In our case, a few pairs of eyes to watch, a camera / video pretty bad and the little we saw through the local media. Anyone can do it. From there, opinion. Because our opinion, ours, yours, we read, the over all is as valid and as necessary as any lawyer (or not) in journalism or news presenter on television. Why was not going to happen, if all we are neighbors and we went through the same streets?

The power of the citizen, the power of who pays taxes and wants that money is used well.

sees a need for studies to assess pages, day to day management of our leaders . Express our opinion that not only every four years, at the polls, but every day, at street level. Who criticize what is wrong and applaud what is good. In public. That our leaders know and feel that are permanently monitoring the position for which we pay . Runs the test every four years and go to continuous assessment. Absolute majorities are not absolute and not become a blank check for any kind of outrage.

Villalba faces in the coming times, new topics that have very sleazy : the location and management model of the new hospital, the redevelopment of Royal Street (needed after years of neglect perhaps premeditated to justify another sweet contract), the widening of the road Navacerrada ... Would you tell someone outside the traditional media, subject always to the economic interests of their respective owners.

About the play, a little more to tell. As you know, ended about two months , but since then it happens every day a worker to tighten a screw or put some trash. Judge for yourself, while we, the finish of the work, those puddles that suggest a poor performance, the road markings nearly invisible, the entrances to the garages a perfect angle, the Barrier curbs on several pedestrian crossings, the missing street, a parking we do not know if it will be widely used, a tunnel perhaps little used, a teleindicators who spends most days hanging that in use, a source quite vulgar we do not know if you run a couple of days in a row, the sculpture of modern art (so modern that few people understand or even notices it), the pyramids we do not know when they will disappear, the pavement to be nice but noisy the pavements to be expensive but it is dirty forever, the trees that never again shall see, those who fell by the wayside ...

This work, besides his many lies has had poor planning ... or maybe not. Perhaps the same contract signed millionaire knew from the beginning that neither the time nor the cost never be fulfilled. Perhaps the builders knew well that, after opening the "black hole" because there was no one in reverse and could continue asking for more and more money while driving at will the pace of the works taking hostage neighbors.

finished now.

Our intention was to criticize some facts and management. not believe we have crossed that line but if anyone has felt personally offended, we apologize for it . An apology which, incidentally, still waiting for our City Council for having troubled and spent (our money) twice promised. If Forrest Gump said stupid is what stupid says, anyone can who affirm that tells lies is a liar . What happens is that many do not believe the stupidity of those lies. And what we have.

We wish to thank especially newspaper El Faro del Guadarrama ", where we got enough information and multiple photos that have helped us to develop some of our items, as has been the only half reported that these works critically, honoring the profession of journalism .

And, of course, thank you very much to all who have passed through these 500 days more or less frequently, which we have illustrated with their comments, their views, criticisms, with your data.

Farewell
A hug to everyone s




--- If this is the first time you visit us and / or do not know what this is, can start to see this summary of blog . You can also browse chronologically (with the file for months at the bottom of the page) or by topic (with different labels below). ---


Monday, February 11, 2008

How To Slipcover A Queen Anne Sofa

monthly summary. 16 .- January-February 2008 Full

In the month of January 2008 published eight articles, and monthly summaries of July, August, September, October and November 2007, whose links can be found at the end of this post.

Day 6 saw the great Christmas present to our City Council made the UTE Cover-Ortiz. On day 9 all together, you and us, a figure surpassed magic. On day 10 we published the 4 th chapter of town meetings. On day 17, the 5 th chapter . On 22
comment
Paripe involving works that have been implemented (and are still running) with deliberate slowness . On 24 linked with a statement of the factory of dreams (who handles the attached photo). On day 25 we paid our town joyfully more than 4 million in fees the pyramids of rubble. Finally, on 30 published the 6 th chapter of town meetings.

February 2008 was our last month. In addition to the monthly summaries of December 2007 and this January and February 2008, published the 1st Chapter 7th Plenary of the Municipal Day 4 we got echo premiere of the new digital daily "El Faro", on 6 published the 8 th chapter the plenary, on 8 9 and the last chapter . Finally, cast on 17 closing the blog, just to meet their 500 days. ---



previous Abstracts:
- October 2006 - November 2006 - December 2006
- January 2007 - February 2007 -
March 2007 - April 2007 - May 2007 -
June 2007 - July 2007 - August 2007 - September 2007
- October 2007 - November 2007 - December 2007

can see them all together by clicking this link . ---



[Post updated 17-Feb-2008 00:20] ---

Friday, February 8, 2008

Blueprints For Rabbit Nest Box

Municipal Collado Villalba (and IX) Full

Extraordinary Plenary on the works of the Municipality of Collado Villalba April 13, 2007 (third and last part)

The remaining agenda items was unrelated to the work. However, surprisingly Case came out as two most .

In Section 5, to approve the Ordinance on saving water:

Ms Joanna Bielicka (PSOE), clarifies that the agreement with the Canal on recycled water is to irrigate public parks at the moment, on counters the cost is 50 euros and the time to install is 5 years, it is public awareness, Ruiz Gallardon has established the same size and has taken two years.

Ms. Carmen Rodriguez (PP), seems that Ruiz Gallardon is his idol, who reiterates that it will buy and who is going to be, you can not accept Worry about other things as forest where they are pouring Cover green lands. [What?]

Mayor, the ordinance aims to raise awareness on water consumption, not to admire a Gallardón , but the city of Madrid is the biggest in Spain and govern who governs has significant legal weight. can not mix with the theme of Mount Cover, Ms. Carreras, when we have snow where skiing [great laughter in the hall] . The Mayor is the first thing you do not like but moving tanks to a landfill Honorio Lozano had expensive work around 500 million pesetas, provisional landfill seemed the best solution, there is an excess of such material, if not, I had left. [Although not stated in the report, in this speech, the Mayor referred to a website critical of Gallardón, created apparently by militants PP]

And in point 6, on the accession to the Network of Cities for Climate.

D. Thomas Alberich (UI) refers to the pyramids Montecover (...)

Mayor (...) [again in full rage] want to add that what the pyramids had not heard so far, the pyramids were used to bury pharaohs, but first had to be dead . Beware lest they betray the subconscious. [Although not on record, this intervention is when the Lord Mayor, a loud voice, said he is proud to be the son of churrero, he is not a pharaoh. Here again that should be shouted "locate and charge" authors of this blog , but did not say on what basis. Interestingly, two seconds before saying ignore "what the pyramids, being so well informed on this blog.]

---

En capítulos anteriores:

- Plenos Municipales en Collado Villalba (I)
- Plenos Municipales en Collado Villalba (II)
- Plenos Municipales en Collado Villalba (III)
- Plenos Municipales en Collado Villalba (IV)
- Plenos Municipales en Collado Villalba (V)
- Plenos Municipales en Collado Villalba (VI)
- Plenos Municipales en Collado Villalba (VII)
- Plenos Municipales en Collado Villalba (VIII)

---

Finalizamos with the series Dedicado a este post lo que dijo if the on these works in the town meetings between March 2006 and April, 2007. Naturally, also spoke of the works in Full before and after this period, but we believe that these samples are sufficient to ensure the democratic spirit that prevails in our City and the adjectives used by the opposition, referring to the management of the government team . why we are confident that when the Mayor get those two things I said (arrogated powers under the Police and judges, respectively), we sat in the dock with all the spokesmen of the opposition and Much of the citizenship of Villalba XDDD ( : - D) -> - <

Wednesday, February 6, 2008

Furnace Common Terminal

Municipal Collado Villalba (VIII)

--- Extraordinary Plenary Hall of Collado Villalba April 13, 2007 the works (Part II)


Point 2 of the Agenda: Amended Draft of the works.

D. Alberto Sánchez (ADEI), it seems like a crusade. At this point, the rate also continued work, ADEI what you want is that the work be completed as before, but this is coupled with approval of an amended. seems that we can not guarantee security if not approved more money. Above all, they want the security of the neighbors, for the record, but no lies . Honorio Lozano (...) The street will be cut with numerous Barrier is a hack more and is a patch . Now he will draft a project save time, cost 1.3 to 5 million. If the business minds are so serious he does not believe that would be left to carry the orders, its credibility would be questioned, here are wrong. The project was bad, and people who have written were wrong.

Ms. Carmen Rodriguez (PP), said in Commission reports that the government team knew how much was to be changed, she thinks that about 4 million euros , you know, not what we mean. Refers to a decree ordering the project, since when you know, you expect to be around 4 million euros. actual occupation of the Library parking is 1% , all this is a deck that's lame lame where is catastrophic is a ruin for the town hopefully be completed soon.

D. Joseph A. Gómez Sierra (PSOE) asks the site management that is present in the Plenary Hall to note that under no circumstances pass 4 million euros. [child says, not the 4-minolles come over "ein?] (...) Here we are doing an excavation of 3 floors, here is it can not do what is done anywhere in the world? [Villalba want a skyscraper!]





Point 3 of the Agenda: Supplemental Draft works.


D. Alberto Sánchez (ADEI), refers to what is being done here can do, no machinery and media, but wants to understand who complain that here is to come forward with the truth . Could being told at the time that the project would be run in two years and no valuation of the time. (...) Financial The economic study is bad , referred to in math two two always equals four, reiterates that the formula of debt to execute the work would have been the most economically advantageous at the end of 20 years been paid little more than 23 million , in 40 years we're going to pay more than 49 million . They opted for a formula for face villabinos does not think the world is managed so poorly resources Hall as here. Refers to the Library parking is ours and we deliver to exploit it for 40 years, and let them sell 70% of squares which are in rotation.

Mayor , going to the point. [and eat XD]

D. Alberto Sánchez (ADEI), this is tremendous, those trees without ecological value according to Gomez and Sierra now have a monetary value, 4 million euros is sad to do a project in this category and is not intended to put trees and banks. Voted no.

D. Thomas Alberich (IU), a question has an environmental impact study forecasts that were made of 568 units of trees, shrubs, street furniture, fencing, etc, do not know this study delivered more than 6 months what it is. "Will be fulfilled, is it legal for the modified is already running? Not the least sought consensus has opted for a modified its air, without anyone's opinion . In the mailbox by the PSOE propaganda more than a year ago, you gave an idyllic image of the end, filled with benches, trees , why Why not bring the change over a year?, bring us an amended with which they disagree, or the procedure or with concrete things, for example, that there are 135 cement planters at a cost between 1088 and 1180 euros each , does not seem the most appropriate way of landscaping, not respond to environmental study, the solution is not good and expensive . Elsewhere, they have sought to make larger islands, the proposed solution is expensive to maintain and aesthetically inappropriate . The separation of rain had to be raised from the initial project cost is crazy , vote against.

Ms. Carmen Rodriguez (PP) refers to the report of the architect at the time of analyzing the initial draft Honorio Lozano, are identified at the trees, benches and landscaping. Now suddenly we have a modified 4 million . (...) It seems that they want to do is take up more millions, it seems that the more expensive, more room there. are using the money in a very irregular , when signing a contract might be compromised money.

Mayor is presented for approval a draft supplementary rejects the tactic of lying in full, this is not a modified, but a complementary works not established in the project and new orders. (...) We are proud of the work being done [again alteradísimo and voices] of having undertaken a year of elections, to provide the city infrastructure necessary parking and to provide the elements to level zero higher quality. We are proud, we have taken steps and the next corporation must also give the necessary steps, are as proud as the day it opens work. (...) On the financial plan of the work, urges caution and explanations ADEI because a thing is the political views and criticize other financial analysis specialist companies.

D. Alberto Sánchez (ADEI), anytime.

Mayor, Councillor data ADEI not supported, you have no idea what he is talking about funding models. It is the first time that has been used at City Hall, has possibly more times .



--- Previous chapters:

- Full Municipal Collado Villalba (I)
- Full Municipal Collado Villalba (II)
- Full Municipal Collado Villalba (III)
- Full Municipal Collado Villalba (IV)
- Full Municipal Collado Villalba (V)
- Full Municipal Collado Villalba (VI)
- Full Municipal Collado Villalba (VII) ---

Monday, February 4, 2008

Review Opinion Atlantis Health Plan

El Faro

El Faro del Guadarrama website debuts that in addition to new and excellent design, updated the news every day. A new information point be missed, not only on Fridays.

If not mistaken, this is the first local media on the Internet with daily updated . A major step in the right direction: the Internet is already the middle of this.

Congratulations


[Now that you have more gigs, as we take the "curriculum" XDDD]


[Please, someone explain "that gives the news" on Channel 7 the difference between browser and search . Thanks.]

---

Updated 5-Jan-2008 (21:15) . Could not be ... According to reports today El Faro, our Mayor has lost loved Lemon Prize, for which has much merit, at the hands of Juan Aragon, Alpedrete (uff, we do not even think how it will be to have won our first mayor ...). Congratulations to the winners. However, according to "tell" (thanks) our biography is not going to attend the Awards Gala (Thursday). We assume it's because his sense of humor is not advised ... ---

Saturday, February 2, 2008

Truglo Night Sights Colt Defender

Monthly Update website debuts. 15 .- December 2007 Full

In the month of December 2007 published six articles, and monthly summaries of May and June of 2007, whose links can be found at the end of this post.

On day 2 we explain how these works were doubled in cost and time , we saw some pictures of the "complete" Battle of Bailen street and we became an echo of a new call for the Orange and Lemon Awards El Faro . Day 8 we got to our helicopter to fly over the pyramids José Pablo I and found that doubling the square footage allowed. Here we do everything in duplicate, is great. To follow the example of things multiply, 13 flying returned, this time on the works Honorio Lozano. Announced on 16 premium and exclusive (as it was Sunday we were the only XDD working medium) the opening to traffic of the street Honorio Lozano , which would occur the next day, and wondering what are the 13 million more than we give them. On 23 parties congratulate everyone world and announce that this blog will have two television news or so. Finally, on 28 put a little joke could well become a reality sometime. Moreover, it would be logical. ---



previous Abstracts:
- October 2006 - November 2006 - December 2006
- January 2007 - February 2007 - March 2007
- April 2007 - May 2007 -
June 2007 - July 2007 - August 2007 - September 2007
- October 2007 - November 2007

[Coming soon ... January 2008 ]

can see them all together by clicking this link .

As always, do not miss the comments made in each of these items : almost all interesting. ---

Friday, February 1, 2008

Wholesale Dutch Master Cigars

Municipal Collado Villalba (VII) Full

Extraordinary Plenary Hall of Collado Villalba April 13 , 2007 the works (first part)


Item 1 of the Agenda: Extension of 5 months within the works.

D. Joseph A. Gómez Sierra (PSOE), considers that there (...) new scope requirements by the council and has been weather conditions without being determinants have had their impact [falsely false, no rain above the average for this time of year] , which is proposed by extending the deadline .

D. Alberto Sánchez (ADEI) Sierra Gómez asked the Information Commission if he slept well and he said yes. He admires not turn red. Is tremendous as it comes back here to lie . (...) Reiterates that is tremendous as come here to lie, has the full minutes of December 15, 2005, which examines some arguments and you already knew that there would be an increase in work, you said that the trees would be a complementary project on the recovery of the mass of trees, and trees Battle of Bailen had no particular value, and before approving a work and knew that I needed. For you no value Trees Battle of Bailen, today it has value, 4 million euros, is tremendous . You talk about fixing Villaljosa Park, but this park was perfect, were the works that have broken, why we have to pay us . (...) Have applied for credit we had saved over 20 million . With the final formula Aracil 49,420,000 going off. [here not yet know the 13 million post]

D. Thomas Alberich (IU), (...) On the score, what was said and suspicions raised in the award, confirmed . For the reduction of time 125 points were awarded to Ortiz-Cover . Commissioning as well as down and in 12 months everything was running made being given 100 points, the other 12, 26, etc . This has not been met by way of the facts. Until now it was speculation, now brings them to be allowed 5 months. have not met the deadline and other aspects of the statement have not met the alternate work schedule, to allow movement of vehicles and people, this gave them 50 points and the other, 5 . awarded to the most expensive in conditions that have not been met . (...) We chose the worst place collapsing the center of the city. None of this is explained, it has awarded the company that was to be awarded. [not on record, but here there was talk of "suspicions" of "cronyism" and "favoritism"]

Ms. Carmen Rodriguez (PP), we believe that today's debate is called elections. You all reports of work, the work was perfect never had been any problem, was impeccable , also spoke of Ortiz, who had dismantled the Windsor. (...) We have a shocking amount of property they are wasting to do the work. This is a hoax, you know, but are forced to adopt it, that is the issue.

D. Joseph A. Gómez Sierra (PSOE), (...) On the run, how to execute the project has not been as drafted, did not fit geotechnical studies facts. (...) With the geotechnical study has been a project, it opens the soil and is not as planned. (...) It refers to a slide with the intervention of firefighters itself [sic] anything, it seems everyone knew how to execute the work under him, way he sleeps like a holy man . [here is where recognized snoring at night, with the peace of duty done, we assume] (...) the report of the technical department of the work claims that the causes are not attributable to the contractor and reported favorably extension.

D. Alberto Sánchez (ADEI), on the issue of term you Mr. Sierra is responsible, you have been saying that his advisers are the best, and then acknowledged that the project is worth, is a bad project, but we keep the same companies for which we continue to counsel. Talk about the weather, the geotechnical [sic] , truth is that this company is given 125 points to be delivered in February Battle of Bailen, why is not completed and turned in the street? , what has to do with Honorio Lozano?. Perhaps not aware of what they are doing, Where are the penalties? you are responsible, we have awarded to a company who does not, for 40 years and now we give a period of 5 months , vote against it.

D. Thomas Alberich (UI), not to recognize and assume to manipulate award is a scandal how has done. That would take political responsibility not want to take, no penalties have been imposed , remember that both are valued aspect of the alternative movement. You said Information Commission which is a project until it begins to open is not known. not been met at all, and nothing happens. This company is given the highest technical score, but then not required to comply, we reiterate that this is a project does not meet anything and nothing happens . When the other companies did not venture down time or other conditions, some might say now.

Ms. Carmen Rodriguez (PP), (...) is not credible that a joint venture we ask for an increase of 40% within , how can a business is willing to ask for 12 months and now 40% more?, That is so trick that no one believes it . Neither of them believe me, there is no possible justification, you choose to project, place, company, run because they were interested, he said yes, now all that is going to hell, hopefully ending in 5 months in this mess that have gotten us, vote against it. Mayor

(...) The project was put out to tender and award made before the two meetings with opposition groups. Everyone said IU less than the best project was to Tecnia, won both the draft and admitted allegations of political groups.

D. Alberto Sánchez (ADEI), that is not true .

Mayor calls for respect. That was done and discussed the issue of trees and improvements to the project. Comes to Honorio Lozano and there a number of problems with the structure of the rock, you have to authorize an increase in time for the completion of the works . [Is in this speech when, alteradísimo, the Mayor said that "all the works are delayed," which is not on record]
---


Previous chapters:

- Full Municipal Collado Villalba (I)
- Full Municipal Collado Villalba (II)
- Full Municipal Collado Villalba (III)
- Full Municipal Collado Villalba (IV)
- Full Municipal Collado Villalba (V)
- Full Municipal Collado Villalba (VI)

Wednesday, January 30, 2008

Best Time To Buy An Audio Receiver

Municipal Collado Villalba (VI)

Collado Villalba March 29, 2007 .


D. Thomas Alberich (IU), [on the 10 th monthly report works] is business as usual, nothing happens, when in fact there has been cracks, evictions, floods , etc, the report seems a joke and an embarrassment . Bring a report with four photos and four figures that is not a report of the project management.

D. Alberto Sánchez (ADEI), asks the following questions:
- Are you going to officially inform the work delay Honorio Lozano-Battle of Bailen?
- Have you checked and occupation of the plot assigned to the UTE Cover-Ortiz?, Is it going to take action?

D. Joseph A. Gómez Sierra (PSOE), tomorrow will be a Commission reports which will be officially informed of the delay which will then come to the House as contracting authority. On the occupation of the plot of ITV, as set out in clause 35 of the sheets looked 20,000 m2. The contractor is responsible for processing the waste. He has a technical report that says the main bunch occupies 16,350 m, and the other just spend lots of 20,000, the occupancy will fade over the next 6 months . [remember that this statement took place in March-2007]

D. Alberto Sánchez (ADEI), who signed the report of Monte Cover?

D. Joseph A. Gómez Sierra (PSOE), D. Polin Juan Guillen.

D. Alberto Sánchez (ADEI) the content of the report is clearly uncertain is disastrous meters that are passed in the area, do not understand how the Environment has not gone already, not understand how they are not falling of shame in relation to these works , we will have a full to talk at length about the work. The initial fence was on the farm was exceeded by far have doubled meters, is willing to accompany him on the measurements, this permissiveness with neighbors is not taken. (...) On architectural barriers are now raising Battle of Bailen again to lower the zebra crossings, not know if the delay is because they are very bad doing the work.

D. Thomas Alberich (IU), asks the following questions:
- How many cracks and "cracks" have appeared on buildings Honorio Lozano Street, next to the tunnel current work-Parking?
- Do you have a deadline for the works? Is it going to impose any penalty on the company by delays ? Is it going to impose any sanction for non compliance with the promise maintenance of traffic during construction transverse?
- The newly opened Battle of Bailen street not compliance with local laws governing non-physical barriers and creating the obligation to provide accessibility to disabled people "are going to work to remedy these defects? How is it possible that this street has been opened completely remodeled and both will cost us all neighbors without forced the company to remove architectural barriers denounced by some neighbors in a while?

D. Joseph A. Gómez Sierra (PSOE) [not answer any of these issues]

D. Thomas Alberich (UI), does not answer the questions you have raised and the council has answered things we have not asked. About cracks or fissures regrets not agree, shows photos, says there are 9 mm. Considered scandalous what is brought to the Information Commission tomorrow, there is a project of additional works, consider outrageous prices, take him to a full ordinary to extraordinary. This is a scandal. seems that the goal is that nobody learns . Considers that the extension of the work comprises things already planned. We will look in detail this project, and if necessary, will take the courts. Some neighbors Villalba arise if the governing PSOE, PSOE Cover or whoever. No specifications have been met or will meet deadlines is a serious issue . Yesterday started to remove the differences of Battle of Bailen, they gave the question a week ago. Architectural barriers in all steps zebras get the same level, so they have to fix it and had to have corrected earlier.

Ms. Carmen Rodriguez (PP), asks the following questions:
- How many square meters of land municipal currently holds the deposit of inert in the area of \u200b\u200bITV?
- How many trees are gone under the waste?
- Does the deposit all authorizations, including the crushing of waste, the Ministry of Environment of the Autonomous Community of Madrid?
- Who is responsible for requiring the licensee of the work the perfect maintenance of public roads by passing trucks that work?
- Has there been any measurement of noise emissions and dust pollution in residential areas of the environment?
- As previously reported the important delay in funding [sic] of the work, Will we have to suffer the residents throughout the summer and noise pollution?
- What solutions do they propose to neighbors who pay our taxes strictly to enjoy our homes?

D. Joseph A. Gómez Sierra (PSOE), in terms of solutions is referred to the homes affected by noise and dust, no one is able to execute a project of this magnitude without noise and inconvenience. To be in area near the landfill space, they must deal with the consequences of a parallel execution of the work, you can not do otherwise, but for the end zone for the inconvenience rather than for the others. As the occupancy rate is hovering the 20,000 m2, there is plot to continue placing. Everyone knew the circumstances in the statement of the plots, not aware that they have disappeared trees, although there is a risk that any disappears, this area is the site where the General Plan, not a park or a protected area . On permits, there is an inspection report on August 1 of the Community of Madrid, Department of Environmental Quality, which has been answered a month later with a report of techniques, the Community of Madrid has understood that it is an activity as part of another core activity, you can transfer the file. On cleaning , the department and the Department of Environment have demanded that they do have a sweeper in the area. Besides the streets needed to perform the work will to replace them again.

Ms. Carmen Rodriguez (PP) in the area of \u200b\u200bthe ITV is being crushed breach current regulations, the area falls on a rain of dust until 9 pm. Do not tell me it's a matter of the work. If you have more occupied meters, pay rent, we have given them an important part of local heritage, if they need more pay meters which . I asked if they have a permit and has not referred in his question to any record because the record is not an authorization, insists that no watering necessary to make a crushing. many trees have disappeared, we are not ciegos. El Área de Medio Ambiente pone multas, pero si es Cover, no . Han hecho baches , se acumulan piedras y barro en las entradas de las urbanizaciones. La barredora fantasma es invisible, le parece indignante, es una vergüenza pública que los vecinos no tenemos porqué soportar. Tienen que mantener las vías en perfectas condiciones, no tenemos por qué sufrir el polvo, el ruido, etc. Deberían tomárselo en serio, no entiende porqué teniendo ustedes los medios para obligarles a cumplir un contrato tan beneficioso para ellos no los utilizan.

D. José A. Gómez Sierra (PSOE), a Cover file has been opened.



--- Previous chapters:

- Full Municipal Collado Villalba (I)
- Full Municipal Collado Villalba (II)
- Full Municipal Collado Villalba (III)
- Full Municipal Collado Villalba (IV)
- Full Municipal Collado Villalba (V) ---

Monday, January 28, 2008

Seattle Sutton Recipes

monthly summary. 14 .-

In the month of November 2007 published five articles, in addition to the summary Monthly April 2007, whose link can be found at the end of this post.

On Day 4 we compare these works with other public works in Barcelona, \u200b\u200b contrasting the difference in attitudes of politicians in both cases. Here we are still waiting for someone to take responsibility for this mess and apologize to the public. We also put a video of which qualify as a return to parliamentary intervention more worthy of our democracy. Day 9 on the bright plan carefully carried out to justify the need for parking and a tunnel. At that time we meet the 400 days of blog. On 12 published the second chapter of these funny Full Municipal Villalba, who sometimes look like a circus three tracks. On day 19, the third chapter . Finally, on day 21 we posted some photos and a survey new sculpture installed in Honorio Lozano, whose result can be seen near the bottom of the page in the right column. ---





previous Abstracts:
- October 2006 - November 2006 - December 2006
- January 2007 - February 2007 -
March 2007 - April 2007 - May 2007 - June 2007
- July 2007 - August 2007 - September 2007
- October 2007

[Coming soon ... December 2007 ]

can see them all together by clicking this link .

As always, do not miss the comments made in each of these items : almost all interesting. ---

Friday, January 25, 2008

Unsubscribe Wordpress

good news in November 2007: 4.17 million in fees

In line with the controversial on charging fees for shop signboards, we read in the same Ordinance (bottom of page 6) something will be great for all villalbinos.

this point is detailed in the fee for " Occupation of public roads or land for public use debris, amounting to 4.40 euros per square meter per month .




In this case we have these numbers:
  • 4, 40 euros
  • 47400 meters square as we saw recently here.
  • 20 months
We take the calculator, multiply those figures out that y. .. we Cover-Ortiz will pay in fees the amount of 4 , 17 million euros (694 million pesetas) to the Municipality of Collado Villalba in the occupation of public space in the Pyramids of JP .

is great news that will redound to the welfare of all, because we are confident that our City will enforce the ordinance in its entirety and everyone equally, just like the rest of Ordinances into force. ---



In case you want to train their brains this weekend, I leave you with a nice sudoku online (you can choose the level from very easy to very difficult):


Thursday, January 24, 2008

What Is Borderline Gestational Diabetes

release from the factory of dreams


---

Communiqué CSOA La Fabrika

+ Photos

will understand that the pictures we've seen the ones you found it funny is this XDDDD

Tuesday, January 22, 2008

When Was Createdosborne And Little

The joint venture Paripe Cover-Ortiz, JP

may remember this article , where a neighbor told us his experience of contact with the service office citizen of the Concessionaire. We talked about that had been well attended and heard. The article is from October 30, 2007. Today, nearly three months , the same neighbor tells us, in a tone obviously very different (that is why today we wrote ourselves), that the situation has not yet been corrected. Tells us that one day passed to remove the broken tile in which complex operation that also broke another withdrew. Today, January 22, 2008, the tiles have been replaced.

Three months after claim no responsibility for the work has had two minutes to handle the job for which he paid.

We have asked many times, most recently in a comment to this article , why say that the works have already finished . As we noted in our response, we terminated works because what they are doing now is a Paripe (see definition in DRAE ). That is, how little is now working on things they could have done for months, and have not done so because they have not liked. Months missing many shots to do and not do so because they want because they want to ensure before charging millions of public money that are missing and we're going to give .

therefore continue to move some workers and some equipment from one place to another without a specific job, until February 28 . As promised. Compliance dates and promises. ---

Sunday, January 20, 2008

Salon Thank You Examples

monthly summary. 13 .- October 2007 Full

First of all, let them know that there interesting comments in the previous post .
And, taking advantage, we recommend the latest Polònia: Me peto a Gallardón . " ---



In the month of October 2007 published eight articles, and monthly summaries of February and March 2007, whose links can be found at the end of this post. It was the month of our first anniversary.

Day 1 we link a press release Sputnik program on a matter which we can deduce that lie in city hall is free. Day 5 was the first and last birthday of the blog, and after congratulating a @ sa otr @ s, we compiled a bonita lista de mentiras . El día 9 anunciamos el próximo " Blog Action Day ", dedicado esta vez al Medio Ambiente. El día 11 colgamos un audio de Sputnik y enlazamos una entrevista con el autor de la escultura que se colocaría en Honorio Lozano.

El día 15 fue el anunciado post del "Blog Action Day", en el que elegimos el tema del cambio climático . El día 17 comenzamos una serie de artículos recogiendo hilarantes escenas de los Plenos Municipales en Villalba. El día 21 comprobamos que es el propio Ayuntamiento quien abre la veda para ensuciar nuestras calles. Finalmente, el día 30 publicamos un email de un vecino counting something positive works. ---



previous Abstracts:
- October 2006 - November 2006 - December 2006
- January 2007 - February 2007 -
March 2007 - April 2007 - May 2007 -
June 2007 - July 2007 - August 2007 - September 2007

[Coming soon ... November 2007 ]

can see them all together by clicking this link .

As always, do not miss the comments made in each of these items : almost all interesting.

Thursday, January 17, 2008

Gratitude Certificate Sample

Municipal Collado Villalba (V)

Collado Villalba January 15, 2007 .

D. Alberto Sánchez (ADEI), performs the following questions:
Who is responsible for the cleaning Honorio Lozano stretch between the work and the Virgin Church Road ?, " why not clean ?

D. Joseph A. Sierra Gómez (PSOE), in terms of cleaning Honorio Lozano's work is contained in the bases and recruitment que corre por cuenta y gasto de la adjudicataria de las obras , tienen una barredora. Medio Ambiente ya les ha girado escritos , se les han comunicado las protestas reiteradas , se les ha instado a corregir la situación en un plazo razonable, si no adoptan estas medidas, la concejalía les abriría expediente según las ordenanzas. [seguro que se acojonaron con esos tremendos escritos; del expediente nunca volvió a saberse]

D. Alberto Sánchez (ADEI), Sobre lo demás, cuando Gómez Sierra quiere y se esfuerza es impresionante, aquí le ha respondido a question without insults or insults , very different from the answer I gave on the Information Commission, I am glad to see that this was the result of a time. Disagree with the explanations, in other cases because it would open the file. It is jumping the company statement day after day, does not understand why they let laugh at villalbinos does not comply with that by which it was awarded. If people do not check it up when he worked at night, they had continued to make, would have loved the work had been finished on time. Do the work has cost more than other products yet not going to meet deadlines . He recalls that the work was a risk of the contractor. Wait the imposition of penalties for non . The that the company offered to do it in less time has cost a fortune .

D. Joseph A. Sierra Gómez (PSOE), there really is no impertinent questions, but answers are irrelevant and questions have no answers . His question was regarding the fines would plan on asphalt. Now you can start saying that the work not completed on time . It has been awarded to a company, a joint venture that is not has not met any of the conditions for the award. The company is complying with the specifications by which it has been awarded.

D. Alberto Sánchez (ADEI), he has not said what he said the councilman, accused of leaving a veiled accusation, he has this data.

Mr. Mayor, you said that the company is not doing anything that came in the statement, this is an accusation that has been repeated. [is right, some have been met: charge]



--- Full Council in Collado Villalba of February 22, 2007 .

D. Alberto Sánchez (ADEI) referred to the full the following questions:
If we were to assess now, after apparently the bid submitted by Cover-Ortiz for the execution of works, " do you think would have the same valuation ?," was imposed any sanctions or open a file as a default ?

D. Joseph A. Sierra Gómez (PSOE), in terms of valuation, has sought the opinion of people who supported the proposal in its day, and following the execution that is occurring, the results are satisfactory . As anticipation of sanction not .

D. Alberto Sánchez (ADEI), sometimes it seems we are talking of different peoples, is shocked at what he said. He has the valuation report was done in his day, and by a number of points earned the highest score of winning company: Deduction measures the impact of works, transverse movement of vehicles and persons , creating of temporary parking spaces, etc. Refers to the work report of September, when the company takes note warning that it will close in tight Honorio Lozano and Battle of Bailen without creating alternative sites. About noise, some people have ended up in the psychiatric [sic] . They had a debate on a television, read what Sierra said, noting that if we had to do ourselves, we had not done so well, and had hired a major multinational firm Clifford Chance. Work delays are due to more land has gone stone, Sierra said in these statements, and likewise that the works were being carried out looking at the safety of neighbors, and that could provide a third shift and would not. Notes Mr. Alderman that this is not true because the third shift was not in the specification and everyone knows that but the neighbors tried to burst over. Attempts have been made that the work is completed in a timely manner and that has not been watching the security situation in neighboring .

D. Juan Concepcion (PSOE), please go ending.

D. Alberto Sánchez (PSOE), protest, said that attacks freedom of expression and reiterates that the difference between the first and second company are 209 points and Ortiz-Cover was given 125 points for doing the work May to April. They also appreciate the commissioning had to be seven months ahead of the forecast of the statements also should be finished well before the underpass, there are 1,500 million difference between one company and another . Ask truth be told on the sanction or disciplinary proceedings, he said he was going to open a file, it is true that the streets remain swept. They are using 20,000 m2 not throw debris but must now bring occupied 35,000 m2. The council said this is a risk and therefore they ask penalties for delays , Today calls the warrant, the government team for less than going to court. If as he said at the risk, if the commission has made the best company in the world, what is required of villalbinos, penalty calls.

D. Joseph A. Sierra Gómez (PSOE), he already assumed the answer would be broad. So his response is simple. We defend our rights have gone to a boundary in the exercise of administrative powers. If all these things are so clear, if they have the documentation is in the perfect right to take appropriate measures, accused of malfeasance . The proposal is signed by the technicians, he has sought to technicians who have signed the assessment how that goes, you in your proposal to govern all the people rose. If you are not satisfied with the answers we give them, you have no other work, which we do when we require compliance with applicable law [jajajaaa, great] .

D. July Henche (PP), asks the following questions:
When the scheduled date for completion of the works in the Battle of Bailen ?
When is provided within the completing the work in the area of \u200b\u200bHonorio Lozano ?
Why have removed the sign announcing the number of weeks remaining to complete the work?
What economic costs borne by successful tenderers for the use of public land for dispose of rubble from the site of the Battle of Bailen Tunnel and Honorio Lozano?. Let us know if you are using for the disposal of other debris from other works.

D. José A. Gómez Sierra (PSOE), he has been in demonstrations against the work and is now concerned about the same The work is already in a very serious phase, the work can be seen, the Battle of Bailen area is expected to open to traffic next week . Honorio Lozano was scheduled to open on May 5, under the contract, not be able to be. As for the issue poster when we had the technical knowledge that could not meet . In terms of cost, no reference is made to the foundation, as the issue of recycling and proximity to the work are meeting the expectations of the statement [XDD] .

D. July Henche (PP), a year ago we all knew that the work on time was not going to end, within the company promised was impossible , fourth part of the assessment was for the term and the partial delivery deadlines. Mr. Mayor said that on 15 January was to inaugurate the flight of Battle Bailen. There was not a work that has been able to deliver on time, and compared it with a presumption Gallardón, which is like comparing a valise with Antonio Bienvenida, one can not compare the car with the work of the M-30. This we knew, we saw it coming, asked whether be finished by Christmas. You will not penalize the company, are not able to enforce the law . Area discharges granted altruistically, that are million donated to the company , the cost of disposal is something that charged by other municipalities and has given here.

D . José A. Gómez Sierra (PSOE) It is not possible to say in relation to the work of Honorio Lozano already knew, if you what they said was that the work was to finish and was going to open on May 5 and out. They did not know or knew anyone. Operators to exploit the work force to realize additional works, such as Telefonica, are performing tasks of strengthening banks, micro, etc. Open the melon is working there, the first is the safety of the work, we have had unpleasant surprises. Should not disturb the neighbors, the Registry Entry is public, there is little discomfort and is progressing work in collaboration with merchants and neighbors. A neighbor has refused to move his vehicle to the library, the rest have been accessed. We have no interest in cutting the ribbon on May 5, the cut off when completed to the satisfaction of villalbinos. Next week will open Battle of Bailen. It will extend the deadlines, we will have a Commission informed. The work on the stretch of Honorio Lozano will end slightly after the May 5 . [juas, juas]

D. July Henche (PSOE). With Honorio Lozano's work we have been fooled , not a work by consensus, on what they have said that it is a work requiring merchants. Under conditions that are doing the work I had done it. have proven totally ineffective, they have no credibility .



--- Previous chapters:

- Full Municipal Collado Villalba (I)
- Full Municipal Collado Villalba (II)
- Full Municipal Collado Villalba (III)
- Full Municipal Collado Villalba (IV) ---